Inefficiency Claims

Subscribe to Inefficiency Claims

When a contractor bids a job, it does so based on a planned sequence of work and productivity of job labor. There are many issues that can arise while building a project that affect labor productivity, and many of those issues are not the contractor’s responsibility. The terms of the contract will often dictate whether a loss of productivity is compensable.

A contractor that suffers a loss of productivity may be entitled to additional compensation. Many methods have been used to calculate loss-of-productivity damages.

In JH Kelly, LLC v. AECOM Technical Services, Inc., a federal court recently considered several different methods for calculating a loss of productivity on a project.Continue Reading Three Ways to Potentially Calculate Lost Productivity Damages

When a contractor’s work on a project is impacted due to no fault of the contractor, the contractor may consider bringing a claim to get paid additional compensation for that impact. Oftentimes, the contractor may assert that its work was delayed, disrupted, or it was otherwise more inefficient than planned.

A contractor asserting a delay, disruption, or inefficiency claim against a project owner can expect the owner to look to any available defenses it has to the claim. After having read many cases involving these types of claims, one can see that the same defenses are frequently asserted.

The top three defenses to delay, disruption, and inefficiency claims include failing to timely submit a contractually compliant claim, waiver / release, and the contract expressly barring such claims. The rest of this post will provide a quick overview of those common defenses.Continue Reading Top Three Defenses Against Delay, Disruption, and Inefficiency Claims

If a contractor is unable to perform its work as efficiently as expected due to the actions of other project participants, the contractor may incur loss of productivity damages. There are many ways to price those types of damages. Some methods are better than others, but the least accepted method is the total cost method.

Under the total cost method, the contractor shows the amount it cost to complete its work and subtracts the contract amount. For example, if the contract amount was $10 million, but it cost the contractor $15 million to complete its work, the contractor might claim that it is owed $5 million.

Courts frequently reject the use of the total cost method because it does not take into account damages that are the result of the contractor’s unrealistic bid or the contractor’s own improper performance of its work.Continue Reading Subcontractor’s Modified Total Cost Claim Allowed to Proceed to Trial

When unanticipated conditions impact a contractor’s ability to perform its work as efficiently as expected, the contractor may consider pursuing a lost productivity or inefficiency claim. There are many ways to price or calculate a contractor’s inefficiency claim damages, some of which can be quite “creative.” Despite the temptation to calculate inefficiency damages in a manner that will create the biggest claim possible, contractors are best served to make their claims as accurate as possible. That is especially true when a contractor must submit its claim to a government owner such as the federal government. In a very recent case, Lodge Construction, Inc. v. United States, the contractor learned its lesson the hard way regarding the submission of inflated inefficiency claims to the government.

In Lodge, the United States Army Corps of Engineers awarded a project to a contractor to rehabilitate a levee in South Florida, which was part of the Corps’ overall “Everglades Update” restoration mission. During construction, the contractor’s cofferdam breached in two sections, flooding the project site. Later, the contractor submitted several claims to the government for three alleged conditions that impacted the contractor’s performance, including constructive changes to the contract specifications and a differing site condition. The contracting officer denied those claims, and the contractor appealed the decisions by filing lawsuits with the United States Court of Federal Claims. Those lawsuits were consolidated, and a five-day bench trial was held regarding the contractor’s claims.

After the trial, the court issued a 46-page opinion in which the court essentially threw out the contractor’s nearly $4 million in collective inefficiency claims against the federal government, because the court found the contractor’s claims were fraudulent. In particular, the court concluded that the contractor’s claims were fraudulent in at least four ways:Continue Reading How NOT to Price an Inefficiency Claim