August 2022

If a construction contractor working on a federal government project is impacted by a government-caused change, the contractor must take steps to preserve its right to obtain additional compensation or time to complete the project. In particular, a contractor must comply with the contract’s claim process. (Click here for the six most common contractor claims.)

Generally, there are three steps to obtaining additional money or time on a federal government project:

1. Submit a request for equitable adjustment: If the government causes a change to the project, the contractor should submit an REA that explains the change, how that change has impacted the contractor’s work, the amount of additional money and/or time to which the contractor is entitled, and backup for the amounts claimed.

Although a contractor is not required to submit an REA before submitting a formal claim, contractors frequently submit the REA first, because it can serve as a starting point for the contractor and the contracting officer to negotiate. The main downside to submitting an REA rather than a claim is that interest will not to start running until a claim is submitted. Also, there is no deadline for the contracting officer to make a decision on an REA.Continue Reading How to Get More Money and Time on Federal Government Construction Projects

As I have stated before, differing site condition claims remain fairly common. They can also one of the most difficult claims for a contractor to prove at trial. There are two types of differing site condition claims–Type I and Type II.

Generally, a contractor may make a Type I differing site condition claim where the contractor encounters a subsurface or latent physical condition at the project site that differs materially from the conditions indicated in the parties’ contract.

Under a Type II claim, a contractor may assert a differing site condition claim where there are unknown and unusual physical conditions at the project site that differ materially from those ordinarily encountered and generally recognized as inherent in work of the character provided for in the parties’ contract.

The United States Court of Federal Claims recently considered a contractor’s $10.5 million differing site condition claim in Nova Group/Tutor-Saliba, Joint Venture v. United States.Continue Reading Contractor’s $10.5 Million Differing Site Condition Claim Torpedoed

I recently gave a presentation on essential construction contract provisions at the annual conference for the Florida Municipal Attorneys Association. Part of my presentation addressed liquidated damages clauses in government construction contracts. After speaking, I was approached with follow-up questions about how to determine the proper daily rate for liquidated damages in construction contracts.

A liquidated damages clause is an owner-preferred contract provision that usually sets a fixed amount for which the contractor is liable to the owner if the project is not finished on time. Often, the amount is set as a certain sum of money per day the project is late (e.g., $1,000 per day).

Generally, liquidated damages provisions are enforceable. But there are circumstances where courts will refuse to enforce such a provision (click here for a recent Florida case where the court found a liquidated damages provision unenforceable).Continue Reading Court Finds Liquidated Damages Clause Unenforceable